Terms and Conditions for Website Design and Development : By placing an order with Finesse InfoTech, you confirm that you are in agreement with and bound by the terms and conditions below. The following terms and conditions are intended to be fair to all parties concerned and to aid in the supply of services. This agreement represents the complete agreement and understanding between Finesse InfoTech and the client. Definitions : The Client: The company or individual requesting the services of Finesse InfoTech. Finesse InfoTech: The website development firm with contractors providing specific website design and development services Payment of Accounts : The website, graphics and any programming code remain the property of Finesse InfoTech until all outstanding accounts are paid in full. A 50% deposit is required after finalizing the Design. Upon final approval of the site design by client, the final deposit is required before all material is submitted to client. Copyright and Trademarks : Finesse InfoTech cannot take responsibility for any copyright infringements caused by materials submitted by the client. The client unconditionally guarantees that any elements of text, graphics, photos, designs, trademarks, or other artwork furnished to Finesse InfoTech for inclusion in the web design project are owned by the client, or that the client has permission from the rightful owner to use each of these elements, and will hold harmless, protect and defend Finesse InfoTech and its subcontractors from any claim or suit arising from the use of such elements furnished by the client. We reserve the right to refuse any material of a copyrighted nature unless adequate proof is given of permission to use such material. Alterations - Maintenance service : The customer agrees that changes required over and above the estimated work or required to be carried out after acceptance of the draft design, charges will included in AMC. Our Maintenance services also take care of your control panel of hosting. The customer also agrees that Finesse InfoTech holds no responsibility for any amendments made by any third party, before or after a design is published. Acceptance of Quotation and Terms and Conditions : The placement of an order for development and/or any other services offered by Finesse InfoTech and validated by the customer's signature on the estimate or quotation form, constitutes acceptance of the estimate or quotation and agreement to comply fully with all the Terms and Conditions and forms a Contract for Business between the signatory and Finesse InfoTech Completion Date and Project Delivery : The client agrees to make available to Finesse InfoTech within 25 days of commencement all materials required to complete the site to the agreed standard and within the set deadline. In the event that the project is delayed past the specified time estimated for completion due to failure to produce the necessary material for completion, Finesse InfoTech will not be responsible for delayed. Finesse InfoTech recommends that clients proceed only when they are ready and able to fulfill these obligations. If at any point during the website development cycle a client wishes to cancel the commission of service, they may do so but will be invoiced an amount that Finesse InfoTech judges at its sole. Potential Disruption of Service : You shall be responsible for obtaining and maintaining all telephone, computer hardware, software, and other equipment needed to access and use this Website. Access to this Website may from time to time be unavailable, delayed, limited or slowed due to, among other things: •hardware failure, including among other things, failures of computers (including your own computer), servers,networks,telecommunication lines and connections, and other electronic and mechanical equipment; •software failure, including among other things, bugs, errors, viruses, configuration problems, incompatibility of systems, utilities or applications, the operation of firewalls or screening programs, unreadable codes, or irregularities within particular documents or other content; •overload of system capacities; •damage caused by severe weather, earthquakes, wars, insurrection, riots, terrorism, civil commotion, act of God, accident, fire, water damage, explosion, mechanical breakdown or natural disasters; •interruption (whether partial or total) of power supplies or other utility of service; •strike or other stoppage (whether partial or total) of labor; •governmental or regulatory restrictions, exchange rulings, court or tribunal orders or other human intervention; or •Any other cause (whether similar or dissimilar to any of the foregoing) whatsoever beyond our control. If access to this Website is unavailable, delayed or limited, or if this Website does not operate quickly and efficiently, you may be unable to transmit your instructions for transactions and other matters, or such instructions may not be promptly executed or you may be unable to retrieve information on a timely basis. If your operations are dependent on such communications with us, and such communications are disrupted or delayed, you may suffer losses. Finesse InfoTech will not be liable for any such loss. Links to other sites : Links to unaffiliated websites are provided solely as pointers to information on topics that may be useful to users of this Website, and we have no control over the content on such unaffiliated websites. If you choose to link to a website we do not control, we make no warranties, either express or implied, concerning your use of or inability to use such site, the content of such site, including the accuracy, completeness, reliability, or suitability thereof for any particular purpose, nor do we warrant that such site or content is free from any claims of copyright, trademark, or other infringement of the rights of third parties or that such site or content is devoid of viruses or other contamination. We do not guarantee the authenticity of documents on the Internet. Links to unaffiliated sites do not imply any endorsement of or responsibility for the opinions, ideas, products, information, or services offered at such sites, or any representation regarding the content at such sites and we expressly disclaim any such endorsement or representation. In addition, these third party websites may have a privacy policy or security practices different from this Website so it is important to read the policies of those sites before sharing your personal information.
HOW WE HELP
We come to client base or directly interact with them and collect exact requirements of customer and then work on it, which leads to better satisfaction of our client.
Home
About us
Services
Careers
Contacts
Terms & Conditions
All Copyrights Reserved 2009 Finesse Infotech